Construction Sub-Contractor Agreement – Instalments determined by Contractor based on Daily rates, No Retention

Construction Sub-Contract (Daily rates, Payment Notice, No Retention)

PROP.CON.11
This Construction Sub-Contract (Daily rates, Payment Notice, No Retention) can be used by a builder who is managing a small scale construction project and who needs to appoint a sub-contractor, such as a plumber, electrician, plasterer or bricklayer.

The Agreement provides for payments to be made in instalments. The payments are not fixed at the outset but are calculated based on daily rates for the Sub-Contractor and his staff. There is the option for the Sub-Contractor to receive an additional payment for materials and expenses. Alternatively, such expenses can be allowed for in the hourly rate. The payment procedure requires the Contractor to serve a payment notice rather than the Sub-Contractor submitting an invoice.

There are no retention provisions. If a retention is required, please use one of our With Retention templates.

If payment is to be made in instalments based on invoices submitted by the Sub-Contractor, please see our Invoiced Instalments Sub-Contracts. If there is simply to be one payment on completion of the Works, please see our Lump Sum Payment templates. If a more robust Sub-Contract template is required, including provisions for variations, extensions of time and liquidated damages, please see our Longer Form Sub-Contracts.

Clause 1 contains definitions. Brief details of the Main Contract need to be given. A description of the sub-contract Works should be inserted in the Schedule.

Clause 2 covers engagement of the Sub-Contractor. This clause confirms the self-employed status of the Sub-Contractor and refers to the Construction Industry Scheme (CIS). This is a HM Revenue & Customs scheme that governs how contractors in the construction industry must handle payments to their subcontractors. Further information can be found at https://www.gov.uk/topic/business-tax/construction-industry-scheme.

Clause 3 deals with timescales. Dates can be inserted for the Works to start and finish. There is a requirement for the Sub-Contractor to rectify any defects that are notified to him within 3 months of practical completion.

Clause 4 sets out the Sub-Contractor’s obligations. These include carrying out the Works in a proper manner, provision of tools and materials and compliance with laws and regulations.

Clause 5 contains the Contractor’s obligations. These cover providing access to the site, providing tools and materials (optional) and compliance with the Construction, Design & Managements Regulations (the CDM Regulations).

Clause 6 relates to liability, indemnity and insurance. There is the option to limit the Sub-Contractor’s liability to a fixed sum.

Clause 7 covers payment. The agreed daily rates must be inserted here. If the Sub-Contractor is to be paid separately for materials and other expenses, the first option in clause 7.2 should be chosen and the second option deleted. If the Sub-Contractor is not to receive any separate payment for expenses, the second option should be chosen. The Contractor is required to submit payment notices on a monthly basis and to pay the amount stated in the notice within 14 days. If the Contractor fails to serve a payment notice the Sub-Contractor may submit a payment application.

Clause 8 deals with non-competition and non-solicitation. These optional provisions protect the Contractor by restricting the Sub-Contractor's ability to provide similar services for competitors and by preventing the Sub-Contractor from "poaching" the Contractor's staff or clients. Both restrictions are subject to optional limitations including time and geographical radius.

Clause 9 is a standard data protection clause.

Clause 10 requires both parties to keep information about the other party confidential.

Clause 11 is a “force majeure” clause. A party will not be held liable for a delay that is caused by an “act of god”.

Clause 12 deals with termination of the Agreement. Either party can terminate if the other is in breach of the agreement or becomes insolvent. The Agreement terminates automatically if the Main Contract is terminated. There is an optional clause allowing no-fault termination by giving 28 days’ notice in writing.

Clause 13 covers dispute resolution and refers to negotiation, mediation, adjudication and arbitration.

Clause 14 contains miscellaneous standard clauses including provisions for the service of notices.

Clause 15 is a jurisdiction clause. The Schedule needs to be completed by the parties with details of the works and the goods, materials and equipment that each party will provide.

Optional phrases / clauses are enclosed in square brackets. These should be read carefully and selected so as to be compatible with one another. Unused options should be removed from the document.

This Construction Sub-Contract (Daily rates, Payment Notice, No Retention) is in open format. Either enter the requisite details in the highlighted fields or adjust the wording to suit your purposes.

Once you have purchased access to the appropriate document folder click on the “Download Document” button below. You will be asked what you want to do with the file. It is recommended that you save the document to a location of your choice prior to viewing.
Top